You are here:

Construction Law/determination of "reasonable time"

Advertisement


Question
Dear Sir. I am quite familiar with the circumstances that lead the contractor to declare time to be "at large", i am concerned however, about the consequences (i.e completing the work in reasonable time)
who makes the determination of the duration of "reasonable time"?
what factors are usually involved that affect such duration?
are there any famous cases that illustrate these points? it would be helpful to read about them -if any-
Thanks for your time
Regards

Answer
Hi Abed
A reasonable time to complete would normally be decided on what actually happened during the progress of the works - based on the facts.
The question being that - taking all factors into account - did the contractor proceed regularly and diligently with the progress of the works AND did he make endeavours to mitigate the effect of delays.
If the contractor did not finish in a reasonable time then damages for non completion are also at large for the period of over run.
In some cases the lawyers may require a form of delay analysis to determine a reasonable time for completion.
Another factor is that the project would be well on the way for completion before time could be set at large so the conduct of the contractor has to be examined throughout the project.
I have researched Atkinson Law for you which has an excelent database of UK law cases:
http://www.atkinson-law.com/library/articleindex.php
I am sure you could google a few more.
Best regards
Mike Testro

Construction Law

All Answers


Answers by Expert:


Ask Experts

Volunteer


Mike Testro

Expertise

Anything related to extensions of time and delay analysis.

Experience

45 years in the Construction Industry 15 Years as a consultant delay analyst - I now hold myself to be expert in this field.

Organizations
Society of Construction Law Adjudication Society ex Planning Engineers Organisation

Publications
6 articles on the relevance of the India Contract Act 1872 and its relevance to modern construction in India. Waiting Publication

Education/Credentials
Associate Member of the Institue of Building

Past/Present Clients
Currently employed in India by Punj Lloyd as expert delay analyst. Engaged in ongoing arbitrations and EoT claims. Prior an Indepenent consultant in delay analysis.

©2016 About.com. All rights reserved.