You are here:

Construction Law/Extension of Time for Subcontractor


Good day Sir,
My question is: can the Subcontractor get an extension of time from the Main Contractor if he was truly delayed by (Employer/Contractor/Other Subcontractors)even if this delay did not result in a delay to the whole project? i.e. the Main Contractor did not get an extension of time from the Employer for that same cause of delay.
Or is the Subcontractor only entitled to an extension of time when the Main Contractor is entitled to it too?
Lastly, if the Main Contractor inserted a clause in the Subcontract to prevent the Subcontractor from getting an extension of time unless he, the Main Contractor, gets it from the Employer (Back to Back), don't it look too harsh on the Subcontractor? can one dispute this clause's validity?
Thank you for your time
Best Regards :)

Dear Abed,

Thank you for your question.

If the Subcontracting Agreement does not provide otherwise, indeed, Subcontractor should get such an EoT, regardless if the Main Contractor did obtained or not.

Especially, if the Subcontractor has been delayed by the Main Contractor, or some of his other subcontractors. In such cases, it is not surprising that Main Contractor does not get and EoT.

If, on the other hand, the Subcontracting Agreement does provide for such a back-to-back EoT, then that is what the Subcontractor has knowingly agreed when entering into the Subcontracting Agreement and if it looks to harsh or not, that is no longer to be discussed at this moment, as it should have been assessed at the time of signing the Subcontracting Agreement.

The only possible analysis may be made eventually under the applicable law, which in some countries allow for an "onerous" contract or clause to be invalidated.

I assume such provision can not qualify to be invalidated under such eventual law, as Subcontractor has had all chances to become aware of it and assess the potential risk, prior signing the Subcontracting Agreement. But one may never know, may worth seeking advice from a local lawyer.

Hope that answer your question.  

Construction Law

All Answers

Answers by Expert:

Ask Experts




Questions related to Civil Engineering Contracts, using FIDIC or other Conditions of Contract, concerning Procurement procedures and documents (pre-qualification, tendering and contracting) and Services/ Works Contracts implementation matters including Determinations, Payments, Time Extensions, VOs, Claims/Disputes. Additionally, questions related to dealing with International Financing Institutions. Can also answer questions in Romanian. Can not answer improperly formulated questions.


Over 20 years of experience in the field of design, works supervision, construction, management of aid funds and technical assistance for various types of contracts implementation, including severe conflictual contractual situations leading to Claims and disputes. Claims/ Contract management, Disputes adjudication, Arbitration.

Member of Romanian Professional Association of Roads and Bridges; Listed on President's List of Adjudicators of Romanian Association of Consulting Engineers Former member of the Disputes Resolution Board Foundation (DRBF) of United States – nominee on DRBF President’s Disputes Board Members List and of DRBF Chapter for Eastern Europe Former member of Polish Association of Consulting Engineers (SIDiR) – nominee on SIDiR President’s Disputes Board Members National List Member of “” volunteers pool Member of the "Constructions Disputes Resolution Services” International Panel of Construction ADR Specialists" of United States

- Graduate in 1994 the Construction Institute - Graduate of several FIDIC,Procurement and other courses - Graduate of first Disputes Board Members Mentoring Scheme ( - FIDIC Accredited Adjudicator

Past/Present Clients
- Several State organisations/Ministries , such as Ministry of Transport, National Admistration of Roads, Ministry of Regional Development (former Ministry of European Integration), Public Works and Housing, Central Contracting and Financing Unit in Romania and also in Turkey, Croatia and Macedonia - Numerous Western based private consultancy companies - full CV and other relevant information available at

©2016 All rights reserved.