Construction Law/Delay Damages

Advertisement


Question
Dear Mr. Femi,

A contract based on FIDIC 1999 Yellow Book, the contractor could not complete the project on time and has now even reached the maximum delay charges imposable (10% of contract amount), the works are still ongoing.

What actions could be taken against the contractor in the light of FIDIC conditions ?

Thank you,

Answer
Dear Huwey,

Thanks for your question and apologies for my late response.

Relying on the provisions of FIDIC 1999 Yellow Book, the sole remedy or damages for Contractor's failure to complete the works at the Contract time for completion as per Clause 8.7 is "delay damages in the amount stated in the appendix to the contract", nothing more, nothing less, this will not change except the contract changed mutually or through courts or any other resolution.

Please note as well that, the 10% is not stated in FIDIC, it could have been stated in your contract probably.

Thanks

Femi

Construction Law

All Answers


Answers by Expert:


Ask Experts

Volunteer


Femi Alofe

Expertise

I can answer all questions relating to the followings: 1. Contract Administration - variations, contract clauses interpretation, all post contract procedures, valuations and certificates questions, extension of time issues and prolongation cost matters. 2. Contract Practice - Any questions regarding forms of contract like JCT, FIDIC & other Bespoke forms. 3. Quantification, measurements and Estimating questions 4. Contracts and construction law questions and dispute resolutions problems. 5. All FIDIC Conditions of contracts

Experience

Out of my 24 years experience in construction industry, i have the following specific experience: 1. Contract Administration - 15 years in contract administration with over 10yrs in Managerial positions covering africa and the middleeast. 2. Contract Practice - 15 years experience with over 10yrs in Managerial and expert positions covering africa, north america and the middleeast. 3. All pre-contract procedures, Tendering, Quantification, measurements and Estimating questions - 20 years experience. 4. Contracts and construction law questions and dispute resolutions problems - 15 years experience with over 10yrs in Managerial and expert positions and 5 years expert witness and active practice in arbitration proceedings covering africa and the middleeast.

Organizations
1. FAIQS - Fellow, Australian Institute of Quantity Surveyors, Australia 2. FRICS - Fellow, Royal Institution of Chartered Surveyors, UK 3. CCP - Certified Cost Professional AACEI, USA 4. PQS - CIQS, CANADA 5. ACIArb. - CIArb, UK 6. MNIQS - NIQS, NIGERIA 7. RQS - QSRBN, NIGERIA

Publications
1. AACEI RP on Estimating, 2010

Education/Credentials
1. B.Tech (QS) 2. RICS professional course, CEM - UK 3. MSc , UK NARIC 4. Professional Doctorate ( to commence 2016)

Past/Present Clients
1. Larsen & Toubro Ltd, Dubai UAE 2. Larsen & Toubro (oman) LLC 3. Archi + Web consortium, Abuja Nigeria 4. George Dike & Associates, Minna Nigeria 5. Public works Authority (Ashghal), Doha Qatar

©2016 About.com. All rights reserved.